LEGAL
The terms that govern your use of this website and our services.
Please read these Terms carefully. They contain important provisions about how you may use this website and engage our services, including disclaimers of warranties, limitations of liability, and a binding arbitration / class-action waiver in Section 14. By using this website or engaging H&Z Installations LLC, you agree to these Terms.
These Terms of Use (“Terms”) are a binding agreement between you and H&Z Installations LLC (“H&Z,” “we,” “us,” or “our”). By accessing or using this website, requesting an estimate, or engaging us for services, you agree to be bound by these Terms and by our Privacy Policy. If you do not agree, do not use the website or our services.
H&Z Installations LLC is a licensed and insured installation, handyman, and moving services company serving Metro Atlanta and the wider state of Georgia. Available services include gazebo installation, fence installation, decking, flooring, house painting, furniture installation, moving services, plumbing, and electrical work, subject to local licensing requirements and availability.
The specific scope, pricing, payment, and warranty for each engagement are documented in a written estimate or contract signed (electronically or otherwise) by you and us (“Service Agreement”). The Service Agreement governs the specifics of the work and supersedes any general statement on this website to the extent of any conflict.
Estimates and quotes provided through this website, by phone, or by text are non-binding good-faith ballparks until confirmed in writing in a Service Agreement. Final pricing depends on on-site assessment, materials selection, scope adjustments, and conditions discovered during the work. Any change to scope after the Service Agreement is signed is documented in a written change order with revised pricing before the change is performed.
You agree to provide reasonable access to the work site at the scheduled time, including any permissions, codes, keys, or unobstructed entry needed. If our team arrives at a scheduled appointment and cannot gain access or begin work through no fault of ours, a trip charge may apply per the Service Agreement.
You agree to keep children, pets, and other unsupervised individuals away from active work areas for safety reasons. You agree to disclose known hazards on the property (loose flooring, pre-existing structural issues, electrical hazards, hazardous materials, etc.) before work begins.
Payment terms (deposit amount, milestone payments, final-payment timing, accepted payment methods) are specified in the Service Agreement. Unless otherwise agreed in writing, payment is due upon substantial completion. Past-due balances may accrue interest at the maximum rate permitted by Georgia law. You agree to reimburse reasonable collection costs, including attorney’s fees, if collection action becomes necessary.
You may cancel or reschedule a service appointment by contacting us as soon as possible (762-394-9693 or Info@hzinstalls.com). Cancellations made fewer than twenty-four (24) hours before the scheduled start may be subject to a cancellation fee stated in the Service Agreement, particularly where materials have been ordered or labor has been committed.
We reserve the right to cancel or reschedule for weather, illness, supplier delays, or other circumstances beyond our reasonable control. We will give you as much notice as possible and rebook at the earliest mutually available time.
Our standard workmanship warranty is stated in the Service Agreement for the specific service performed. Manufacturers’ warranties on materials we install are governed by the manufacturer and are not extended or expanded by H&Z. To make a warranty claim, notify us in writing at Info@hzinstalls.com within the warranty period, describing the issue. We will respond promptly and, where applicable, schedule a return visit at no cost.
The warranty does not cover damage from misuse, normal wear and tear, weather events, modifications by third parties, lack of recommended maintenance, or pre-existing conditions on the property.
Unless you tell us otherwise in writing, you grant H&Z a non-exclusive, royalty-free right to take photos and videos of completed work at your property (exterior or interior, no people identifiable without their consent) and to use those images in our portfolio, website, social media, advertising, and proposals. To opt out, email Info@hzinstalls.com before work begins or at any time after.
The H&Z Installations name, logo, color palette, and the content of this website (text, images, design, layout, code, structured data) are the property of H&Z Installations LLC or used with permission, and are protected by copyright, trademark, and other laws. You may view, download, and print pages for your personal, non-commercial evaluation of our services. You may not reproduce, distribute, modify, create derivative works from, publicly display, or otherwise exploit any portion of this website for any commercial purpose without our prior written consent.
Photos may show work completed under conditions different from yours; we make no representation that your project will look identical to a portfolio piece.
You agree not to: (a) use this website in any way that violates applicable law; (b) attempt to gain unauthorized access to any portion of the website or its underlying systems; (c) probe, scan, or test the vulnerability of the website; (d) introduce viruses, trojans, worms, or other malicious code; (e) scrape, harvest, or extract data from this website using automated means without our written consent; (f) impersonate any person or entity; or (g) interfere with any other user’s use of the website.
This website is provided “as is” and “as available”. To the fullest extent permitted by Georgia law, H&Z Installations LLC disclaims all warranties of any kind regarding the website, whether express, implied, statutory, or otherwise, including but not limited to implied warranties of merchantability, fitness for a particular purpose, and non-infringement. We do not warrant that the website will be uninterrupted, error-free, secure, or free of viruses; nor do we warrant the accuracy, completeness, reliability, or currency of any information on it.
Service warranties for actual installation, handyman, or moving work are governed exclusively by the Service Agreement for that work — not by this website.
To the fullest extent permitted by Georgia law, in no event will H&Z Installations LLC, its members, managers, employees, or contractors be liable to you or any third party for any indirect, incidental, special, consequential, punitive, or exemplary damages (including lost profits, lost data, loss of goodwill, business interruption, or any other intangible losses) arising out of or related to your use of this website — even if we have been advised of the possibility of such damages.
To the maximum extent permitted by law, our aggregate liability to you for any claim arising out of or related to your use of this website (separate from our services performed under a Service Agreement) is limited to one hundred U.S. dollars ($100). Liability for services performed under a Service Agreement is governed by that Agreement.
Nothing in these Terms excludes or limits liability that cannot be excluded or limited under applicable law, including liability for gross negligence, willful misconduct, or fraud.
You agree to indemnify, defend, and hold harmless H&Z Installations LLC and its members, managers, employees, and contractors from and against any claims, liabilities, damages, losses, and expenses (including reasonable attorneys’ fees) arising out of or in any way connected with: (a) your access to or use of this website; (b) your breach of these Terms; (c) your violation of any law or the rights of any third party; or (d) any content you submit to or through the website.
Please read this section carefully — it affects your legal rights.
Any dispute, claim, or controversy arising out of or relating to these Terms or to your use of this website that is not resolved through good-faith informal negotiation within thirty (30) days of written notice will be resolved by binding individual arbitration administered by the American Arbitration Association (AAA) under its Consumer Arbitration Rules, in Atlanta, Georgia. The arbitrator may award the same damages and relief as a court could. Judgment on the award may be entered in any court of competent jurisdiction.
You and H&Z each agree that any dispute resolution proceedings will be conducted only on an individual basis and not in a class, consolidated, or representative action. You waive any right to participate in a class action or class arbitration against H&Z.
This Section 14 does not prevent either party from seeking injunctive or equitable relief in court to protect intellectual-property rights or confidential information, or from bringing an individual claim in small-claims court for matters within that court’s jurisdiction.
This arbitration clause does not apply to disputes regarding services performed under a Service Agreement to the extent that Service Agreement provides a different dispute resolution mechanism.
Neither party will be liable for delay or failure to perform any obligation under these Terms or any Service Agreement to the extent caused by events beyond its reasonable control — including acts of God, severe weather, fire, flood, earthquake, pandemic, epidemic, governmental action, civil unrest, labor disputes, supplier failures, or interruptions of utilities or transportation.
This website may contain links to third-party websites (Thumbtack, Facebook, Google Maps, suppliers, etc.). Those sites are governed by their own terms and privacy policies, and we are not responsible for their content, products, or services.
These Terms are governed by the laws of the State of Georgia, USA, without regard to its conflict-of-laws principles. Subject to the binding arbitration in Section 14, any court proceedings will be brought exclusively in the state or federal courts located in Fulton County or DeKalb County, Georgia, and you consent to the personal jurisdiction of those courts.
We may update these Terms from time to time. Material changes will be highlighted on this page for at least thirty (30) days. Your continued use of the website or our services after a change takes effect constitutes acceptance of the updated Terms. If you do not agree to the updated Terms, you must stop using the website.
If any provision of these Terms is found unenforceable, the remaining provisions remain in full force and effect. These Terms, together with the Privacy Policy and any signed Service Agreement, constitute the entire agreement between you and H&Z regarding the subject matter and supersede any prior agreements on that subject.
H&Z Installations LLC · Info@hzinstalls.com · 762-394-9693 · Atlanta, Georgia, USA.
Send a quick message — we’ll reply during business hours.
Main line